37 1 5MB
FIDIC Yellow Book Training Training to VSMC 2014
CONTENTS 1.
Presentation slides
3
2.
FIDIC Notes – part one
180
3.
FIDIC Notes – part two
214
© Driver Trett 2013
www.drivertrett.com/europe
Managing FIDIC Contracts Training to VSMC – 2 day workshop 2014 Mark Castell – Regional Managing Director [email protected] www.drivertrett.com
Managing FIDIC contracts Introduction Contract management - some general principles The FIDIC standard forms – overview & differences Management of a FIDIC Yellow Book Contract throughout a project The Tender Phase Award of Contracts Setting up the project Procurement and sub-contracting The execution phase Completion & handover Resolution of financial matters (and disputes if any) Conclusions
2
What we do Our dispute and advisory team, delivering high-level commercial and claims support, procurement advice, contractual and strategic advice, and the full range of planning and programming services. Our project controls team, delivering commercial management, quantity surveying, and planning services throughout the project lifecycle.
Provision of a range of specialised services based around investigative and forensic skills. Working with clients within the financial sector including banks, funders, investors, accountants, and lawyers Provision of project management alongside transaction advisory services to clients for the delivery of concession projects using PFI, PPP and DBFO procurement options..
World-class quantum, delay, and technical experts for litigation and provision of internationally experienced adjudicators, arbitrators, and mediators.
GROUP OVERVIEW
• Driver Group is a global construction consultancy, providing construction and engineering focused services since 1978 • Stock exchange listed plc. – AIM (2005) • Driver Trett established in 2012 when Trett Consulting became part of the Driver Group. • Market leader in expert witness, planning, commercial and disputes. • Over 330 global staff. • Network of offices across Europe, Africa, Americas, Asia Pacific, and the Middle East. • Global reach with projects undertaken worldwide.
DRIVER GLOBAL PRESENCE
Contract management some general principles
6
Some questions …
Q: What is common to every project? A: A Contract.
Q: What is a Contract? A: Simply speaking, it is an agreement. Q: What is the objective of a contract? A: To define the relationship and how the parties act – the ‘rules of the game’. 8
Q: What is contract management and what does it cover? A: Management of: Risks & opportunities Change Entitlement Claims The Client It should include the avoidance of Disputes
Or is it simply, good management
9
Q: When should the management of contracts begin? A: At the conception of a contract.
Q: When should the management of contracts end? A: At the finalisation of all matters. 10
Contracts involve a process – ‘conception to grave’ Receipt of an enquiry Tender or bid phase Negotiation and award Design or engineering phase Procurement phase Construction phase Defects liability phase Finalisation of all matters 11
Q: Who is involved in managing a contract? Revised Q: Who should be involved in managing a contract? A: Everyone within the business...
Does this happen?
12
Introduction to FIDIC
13
FIDIC (Fédération Internationale des Ingénieurs-Conseils) Federation of national associations of consulting engineers Based in Geneva Founded in 1913 with original founding members from France, Belgium and Switzerland UK joined 1949, USA joined 1958 Seen as international from 1970s and members from about 70 counties
FIDIC aims High ethical standards High professional standards Development of engineering profession in developing countries
FIDIC documents Standard Forms of Contracts Guides to Standard Forms of Contracts Tendering procedures Model Agreements
Standard Forms of Contract
17
History of FIDIC Standard Forms of Contract In 1957 the original Red book for works of civil engineering construction was published. Further editions and supplements were published up to 1996. Modelled on ACE form of contract which was based on ICE conditions of contract. The original Yellow book for electrical and mechanical work reached third edition in 1987. The original Orange book was first published in 1995 for design and build – turnkey works.
General principles of FIDIC Standard Forms of Contract Historically based on Anglo Saxon type contracts. Drafted for general use on an international basis. Modifications may be required in some jurisdictions. FIDIC standard forms are generally accepted to be well-written and capable of being understood by users. They recognise there will be problems and potential for conflict and dispute on projects but set out processes to resolve them including: Placing a significant administrative burden on the parties and; requiring the parties to deal with issues at the time.
The Current FIDIC Standard Forms of Contract
20
Current FIDIC Main Standard Forms of Contract
Blue (2006)
Yellow (1999)
Green (1999)
Red (1999)
Silver (1999)
Pink (2010)
Gold (2008)
Current FIDIC Main Standard Forms of Contract Blue book. Dredgers Contract
Green book. Short Form
Red book. Construction Contract
Pink book. MDB Construction Contract
Current FIDIC Main Standard Forms of Contract
Yellow book. Plant and Design-Build Contract Gold book. DBO Contract
Silver book. EPC/Turnkey Contract
When do you use which standard form? For dredging & reclamation works, the Blue book
Otherwise, which contract should be used? STRAIGHTFORWARD PROJECT ?
no
< $500K or < 6 months
EMPLOYER DESIGN ?
yes
no yes
CONTRACTOR DESIGN
no
plant and/or high unforeseen risks yes
little employer involvement no major unforeseen risks
Maintenance yes
yes
no
Silver book - EPC Turnkey concept Contractor provides a complete facility that is ready to operate when the Employer turns the key Employer ‘steps back’ Only appropriate in certain situations
Consequences Greater risk transfer to Contractor Increased tender prices Opportunity for extensions of time and financial claims reduced More certain final price for Employer
Overview of Current FIDIC Standard Forms of Contract
27
Generally – Red, Yellow & Silver Books FIDIC produces the General Conditions (20 clauses) and anticipates separate Particular Conditions to be used for project-specific changes and / or revisions due to applicable law. Appendix to Tender also used to contain project-specific information. Definitions set out in clause 1. Importance of Letter of Acceptance – binds Parties to Contract. Contract Agreement only confirms binding Contract is in place (if Letter of Acceptance is used). Communications shall be in writing, transmitted using specific methods and issued to stated addresses (clause 1.3). Applicable law and ruling language needs to be stated (clause 1.4). Priority of documents provisions (clause 1.5).
General concepts – Red Book
Adopts the role of an Engineer who can vary Works Responsibility of design with the Engineer acting on behalf of the Employer Tenderers issued with Specification, Drawings and Schedules (includes BoQ) Payment on a re-measurable basis (but option for lump sum) Responsibility for unforeseen conditions with Employer DAB appointed at outset of project to resolve disputes
General concepts – Yellow Book
Adopts the role of an Engineer who can vary Works Responsibility of design (fitness for purpose) with the Contractor Tenderers issued with Employers Requirements Payment on a lump sum basis (but option for re-measurable ) Responsibility for unforeseen conditions with Employer DAB appointed at outset of project to resolve disputes, or ad-hoc
General concepts – Silver Book
Employer’s Representative instead of Engineer. Prime duties restricted to monitoring progress, quality and testing Responsibility of design (fitness for purpose) with the Contractor Tenderers issued with Employers Requirements Payment on a lump sum basis Responsibility for nearly all risk with the Contractor DAB appointed at outset of project to resolve disputes, or ad-hoc
Format of the FIDIC books
32
Standard Format for the Red, Yellow and Silver books 1. General Conditions – 20 Clauses
2. Guidance for the preparation of Particular Conditions
3. Forms of letter of Tender, Contract Agreement (including Appendix to Tender), Dispute Adjudication Agreement and Forms of Securities
33
Red Book General Conditions
Clause 1 - Definitions, General Provisions Clauses 2 to 4 - Duties of the Employer, the Engineer and the Contractor Clauses 5 to 7 - Resources (staff, labour, materials) Clauses 8 to 10 - Time Clause 11 - Defects Liability Clauses 12 to 14 - Payments Clauses 15 to 16 - Termination Clauses 17 to 19 - Risk and Insurance Clause 20 - Claims and Disputes
34
Yellow Book General Conditions
Differs as: Clause 5 - Design Clauses 12 – Tests after Completion
35
Silver Book General Conditions
Differs as: Clause 3 - Duties of the Employers Representative
36
Exercise Low
High
Employer design
Re-measurable
Contractor design
Lump Sum
1. Match each book with a description of design responsibility. 2. Match each book with a description of valuation. 3. Arrange in the order of risk to Contractor (low to high).
Answer Low
High
Employer design
Contractor design
Re-measurable
Lump Sum
The management of a FIDIC Yellow Book contract
39
A FIDIC YB contract entails management of:
A tendering process or period
Preparation of enquiry documents
Contractor’s sets its commercial strategy and issues its offer
Discussion / negotiation
Award of the contract
Agreement reflects a common understanding
How is the offer accepted?
Setting up the project
Internal – knowledge transfer and project specific systems
External – submittals and kick-off meeting
Procurement and sub-contracting
Step down / flow down principles versus practice
The use of the phrase ‘Back to back’ 40
A FIDIC contract entails management of:
The execution phase
Progress control / updates
Financial matters & payment
Change / claims
Suspension
Force Majeure
Completion and Handover
Takeover
Tests
Defect liability
Resolution of financial matters (and disputes, if any)
Dispute resolution
41
The tender stage
Photograph credits to FreeDigitalPhoto.net & Grant Cochrane
Typical Sequence of Events
Issue of Tender Documents
Submission of the Tender Yellow book Cl. 1.1.3.1 Base Date
28 days
Preparation of Tender Documents
Tender Period
43
An Employer has to: Draft the Particular Conditions (see guidance notes)
44
Risk allocation:
Risk should be allocated to the party best able to manage it.
Standard Forms of Contract (such as one of the FIDIC forms) generally allocate risk reasonably and fairly.
Major revisions to Standard Forms of Contract should be considered carefully.
45
An example VSMC contract Installation of export & array cables - London Array project
One document called ‘Conditions of Contract’
States “these … are based on FIDIC Conditions of Contract for Plant and Design-Build First Edition 1999”
No separate General and Particular Conditions of Contract
22 Clauses
Do you consider this: 1. Is an advantage to the contractor? 2. Adds or reduces work at tender stage? 3. Adds or reduces risk to the contractor?
Some Contracting Risks 1.
Clear scope of work
2.
Provision of bonds, guarantees
3.
Security for payment
4.
Physical conditions and access
5.
Practicality of schedule dates
6.
Use of specialist suppliers/sub contractors/ third parties
7.
Extension of time provisions
8.
Safety provisions
These risks have to be provided for in the contract
More Contracting Risks 1.
Clarity of the contract wording and provisions (no discrepancies)
2.
Wording and provisions that can be easily understand by all concerned
3.
Document submittals at, or just after commencement
4.
Conditions precedent clauses
5.
Notice requirements
6.
Requirement for record keeping
7.
Change process
8.
Claims process
These risks also have to be provided for in the contract
An Employer has to: Draft the Particular Conditions (see guidance notes) Draft the Employers Requirements
49
Employer’s Requirements According to Clause 1.1.1.5, ERs must specify (cannot imply) for each part of the works The purpose The scope The design Other technical criteria
Satisfying the Employer’s Requirements shown by successful Tests on Completion
Responsibility for errors in the Employer’s documents Yellow book Clause 5.1 provides for a period for the Contractor to identify errors If any found within period, corrected and treated as Variation if it is deemed that “an experienced contractor exercising due care” would not have found it pre-tender. Under Clause 1.9, if any found outside of period, becomes a claim if it is deemed that an experienced contractor would not have found it pre-tender.
Fitness for purpose
Yellow book Clause 4.1 provides an obligation that the Works be “fit for the purposes for which the Works are intended as defined in the Contract”
The obligation for fitness for purpose is more onerous that designing with “due skill and care” i.e. Suitability of end product versus design process
London Array project has amended wording. ‘Works shall conform to the Employer’s Requirements as defined in or reasonably inferred from the Contract.’
Fitness for purpose continued Responsibility for fitness for purpose cannot be passed to anyone else or insured Yellow book Clause 4.1 also provides an obligation to provide all Works “necessary for stability or for completion, or safe and proper operation of the Works”
Satisfying Fitness for Purpose shown by successful Tests on Completion
An Employer has to: Draft the Particular Conditions (see guidance notes) Draft the Employers Requirements Complete the Appendix to Tender
54
An Employer has to: Draft the Particular Conditions (see guidance notes) Draft the Employers Requirements Complete the Appendix to Tender Provide a Letter of Tender
55
An Employer has to: Draft the Particular Conditions (see guidance notes) Draft the Employers Requirements Complete the Appendix to Tender Provide a Letter of Tender Provide Site Data (Clause 4.10)
56
An Employer has to: Draft the Particular Conditions (see guidance notes) Draft the Employers Requirements Complete the Appendix to Tender Provide a Letter of Tender Provide Site Data (Clause 4.10) Draft the Instructions to Tenderers (if required)
See also the Notes on the Preparation of Tender Documents
57
Clarity is important as a Contractor must understand what will be expected of him in order to: Recognise the responsibilities and risks Quantify the responsibilities and risks Evaluate the responsibilities and risks
Plus… identify the opportunities.
This sets the basis for a Contractor’s commercial strategy for the project 58
Are these opportunities that exist at tender stage?
To understand the employer needs
To see whether the proposed contract describes the same thing
To influence the client’s way of thinking
To influence the provisions of the contract (terms and conditions)
To influence the allocation of risk
To agree the duration for undertaking the works
To agree the price for undertaking the works
To agree security of payment
etc 59
Exercise 8 days prior to tender submission the Employer provides further sub-surface data which contradicts data issued previously. The Contractor however, ignores the new data in his tender. The tender is successful and the Contractor is awarded the project. It then subsequently claims on the basis of unforeseeable physical conditions. a) Consider the relevant clauses and issues. b) Consider the various ways in which the Employer could have acted prior to Tender when issuing the revised data. c) Consider the various ways in which the Contractor could have acted when the revised data was received. d) Consider what the Contractor’s position might be. 60
Yellow Book – relevant clauses
Clauses 1.3, 3.1 & 4.3 – why?
Clause 4.10 – Employer to make available all relevant site data. Contractor responsible for interpretation and inspecting site.
Clause 4.11 – Sufficiency of tender.
Clause 4.12 – unforeseeable and adverse physical obstructions by an experienced Contractor.
Clause 1.1.6.8 – definition of unforeseeable
See also Clause 20 Claims
61
A Contractor will then submit its tender or offer
Yellow book Under cover of a Letter of Tender
62
Period leading up to Contract Award
63
Typical Sequence of Events
Issue of Tender Documents
Submission of the Tender
Contract award
Yellow book Cl. 1.1.3.1 Base Date
28 days
Preparation of Tender Documents
Tender Period
Discussion & negotiation
64
Prior to contract award
Employer has to undertake comparisons of tenders
Both parties have to negotiate their best position
Agreement should reflect a common or mutual understanding
The agreement should be explained in the Contract
65
Contract award
66
A Contract is an agreement, which should be based upon the mutual understanding that was built up in the tender stage.
67
Employer Letter of Acceptance signifies the contract coming into full force Refer definition at Clause 1.1.1.3 – includes annexed memoranda
Contract Agreement either follows, or used instead of a Letter of Acceptance
68
The inital period after award
69
Exercise
Under a Yellow Book project, consider...
What is / should be the internal process for transferring the knowledge already gained by the business? How / when do you assess the specific contract management requirements of your projects? How should kick-off meetings with the client be used?
70
Exercise
Under a Yellow Book project, consider...
The documents that the Contractor should expect to submit after receiving the Letter of Acceptance The documents and other ‘things’ that the Contractor should expect to receive from the Employer and/or his representative after receiving the Letter of Acceptance
71
Some other issues to consider
72
Some particular concepts
1. Evidence of ability to pay 2. Value Engineering 3. Impartiality of the Engineer 4. Contractor design submittals
Evidence of Ability to Pay Clause 2.4 states
“the Employer shall submit, within 28 days after receiving any request from the Contractor, reasonable evidence that financial arrangements have been made and are being maintained which will enable the Employer to pay the Contract Price (as estimated at that time) in accordance with Clause 14. ...”
74
Evidence of Ability to Pay - issues
Requires a request by the Contractor
What constitutes “reasonable evidence” ? A letter of confirmation from the Employer… A letter from the source of funding…
The relevant amount includes changes made under the contract i.e. it is not just the tender sum
Evidence of Ability to Pay Clause 2.4 continues “If the Employer intends to make any material change to his financial arrangements, the Employer shall give notice to the Contractor with detailed particulars.”
76
Evidence of Ability to Pay – further issues
The obligation to give notice of change does not seem to require a request from the Contractor
Options available for non compliance Contractor may slow or suspend work or even terminate the contract (Clause 16 refers)
London Array Project has amended provisions. Employer to provide a Parent Company Guarantee.
Value Engineering Clause 13.2
Clause 13.2 seeks to encourage the Contractor to propose changes to nature or construction of the works that will be beneficial to the Employer
Red book – savings to be shared and any subsequent design is to be by Contractor and fit for purpose at Contractor’s risk
Yellow & Silver Books- financial benefits to be proposed by Contractor 78
Impartiality of the Engineer Clause 3.1 states (red and yellow books)
“…Except as otherwise stated in these conditions: Whenever carrying out duties or exercising authority, specified in or implied by the Contract, the Engineer shall be deemed to act for the Employer. …”
79
Impartiality of the Engineer Clause 3.1 states (red and yellow books)
“…Except as otherwise stated in these conditions: (a) Whenever carrying out duties or exercising authority, specified in or implied by the Contract, the Engineer shall be deemed to act for the Employer. (b) …”
80
Impartiality of the Engineer Clause 3.5 gives the exception …
“Whenever these Conditions provide that the Engineer shall proceed in accordance with this Sub-Clause 3.5 to agree or determine any matter, the Engineer shall consult with each Party in an endeavour to reach agreement. If agreement is not achieved, the Engineer shall make a fair determination in accordance with the Contract, taking due regard of all relevant circumstances.”
81
Impartiality of the Engineer Clause 3.5 gives the exception …
“Whenever these Conditions provide that the Engineer shall proceed in accordance with this Sub-Clause 3.5 to agree or determine any matter, the Engineer shall consult with each Party in an endeavour to reach agreement. If agreement is not achieved, the Engineer shall make a fair determination in accordance with the Contract, taking due regard of all relevant circumstances.”
82
Impartiality of the Engineer - Issues 1.
Impartiality versus fairness
2.
Fair determination “in accordance with the Contract” i.e. interpretation of the Contract…but the Contract may not be fair
3.
Partiality is only “whenever carrying out duties or exercising authority, specified in or implied by the Contract” i.e. does not include negotiation on behalf of Employer
4.
Silver book there is no Engineer and the Employer makes the (fair) determination
83
Contractor design submittals
Yellow book Clauses 5.2 deals with submission of documents Yellow book provides for submission for “review and/or for approval”
Exercise
Yellow book The Contractor submits design documents for approval. Two weeks later the Engineer responds pointing out that the designer had not been submitted for his approval, and that the Contractor has provided insufficient details of a particular component. The Contractor (i) immediately starts the production of working drawings, (ii) 3 days later commences manufacture.
What action should the Engineer take?
85
Procurement and sub contracting
Sub-contracting issues
Obtaining consent to sub-contract works When? From whom?
87
Clause 4.4 states the Contractor: “… shall not subcontract the whole of the Works. … shall be responsible for the acts and defaults of any Subcontractors… as if they were the acts and defaults of Contractor. … shall not be required to obtain consent for suppliers of Materials, or a subcontract … named in the Contract. The prior consent of the Engineer shall be obtained to other proposed Subcontractors. … shall give the Engineer not less than 28 days notice of the intended date of commencement of each Subcontractor’s work…”
Sub-contracting issues Which terms and conditions are to be used? Are the FIDIC Standard Forms of Contract to be used? If so, how will the main contract and sub-contracts be aligned? Back to back – what is it?
89
Example – use of the phrase ‘back to back’ “Please accept this telefax as your letter of intent for the [X] Scope of Work for the [Y] project. Total price €……..excluding pipe supports, which will, be calculated at a rate of €…/kg (delivery and installation). The contractual terms shall be on a back-to-back basis in accordance with the terms of the Main Contract. Currently, parts of the Main Contract are under discussion with the Client. The results eventually be incorporated in the Main Contract, which will be issued to you when available. This Letter of Intent is based on the mutual understanding that: 4. Shift working/overtime/weekend work shall be carried out as and when required and is included in the above mentioned price. 5. The order is based on the Back to Back principle. You are requested to return a signed copy of this telefax, thereby unconditionally agreeing to the above outlined conditions.”
90
Back to Back Do not rely on the phrase but actively align relevant parts of main and sub-contracts. Alignment is particularly required on: 1. Technical requirements Performance criteria Materials and Workmanship standards 2. Contractual requirements HSQE / Business ethics Termination / suspension Warranty Insurance 3. Procedural requirements Completion, testing and commissioning protocols Compliance regimes
Sub-contracting issues Which terms and conditions are to be used? Are the FIDIC Standard Forms of Contract to be used? If so, how will the main contract and sub-contracts be aligned? Back to back – what is it? Changing names – does it work? Are VSMC standard forms of sub-contract to be used? If so, how will it align to the main contract? Is the FIDIC Standard Form of Sub-contract be used? If so, how will it align to the main contract?
92
Execution phase
Typical execution phase issues
Time - monitoring or reporting progress
Valuation and payment
Change / variations
Claims for time and money
Suspension of the works
Claims
Suspension
Force Majeure
94
Time Issues
95
Clause 8 – programmes Clause 8.1 – notice of Commencement Date Clause 8.2 – Time for Completion Clause 8.3 – Programme to be provided within 28 days of Notice to Commence – detailed Clause 8.3 – Engineer has 21 days to reject Clause 8.3 – Contractor to proceed in accordance with it Clause 8.3 – revised programmes to be submitted in various situations London Array project has amended provisions Clause 8.2 concerns rate of progress and notice of delay
96
Exercise – Yellow book The Contractor has submitted its programme under Sub clause 8.3 and receives a response from the Engineer within 21 days. The reply says that the programme is not approved since the Engineer does not agree with the duration allowed for some of the activities.
What should the Contractor do?
97
Critical path
The Critical Path - Why it is important? Determines the earliest completion date for the project. Determines the earliest and latest completion dates for individual activities. Calculates float. Identifies which activities are important to the completion of the project. Identifies areas of risk. Identifies areas where action should be taken to reduce the project duration or recover from delays.
The Critical Path - Shortest route between work and the pub
Critical path analysis
New Wall No Activity
Time (days) 1
2
3
4
5
6
7
8
9
10 11 12 13 14 15 16 17 18 19 20 21 22 23
1 Excavate the trench 2 Pour the foundation 3 Raise the brickwork 4 Place the coping 5 Complete 6 7 8
Link
Activity
Critical path analysis
New Wall No Activity
Time (days) 1
2
3
4
5
6
7
8
9
10 11 12 13 14 15 16 17 18 19 20 21 22 23
1 Excavate the trench 2 Pour the foundation 3 Raise the brickwork 4 Place the coping 5 Complete 6 7 8
Critical Critical Activity Link
Critical path analysis
New Wall No Activity
Time (days) 1
2
3
4
5
6
7
8
9
10 11 12 13 14 15 16 17 18 19 20 21 22 23
1 Excavate the trench 2 Pour the foundation 3 Raise the brickwork 4 Place the coping 5 Complete 6 Design 7 Order concrete 8 Order bricks
Critical Critical Activity Link
Critical path analysis
New Wall No Activity 1 Excavate the trench 2 Pour the foundation 3 Raise the brickwork 4 Place the coping 5 Complete 6 Design 7 Order concrete 8 Order bricks
Time (days) 1
2
3
4
5
6
7
8
9
10 11 12 13 14 15 16 17 18 19 20 21 22 23
Critical path analysis
New Wall No Activity 1 Excavate the trench 2 Pour the foundation 3 Raise the brickwork 4 Place the coping 5 Complete 6 Design 7 Order concrete 8 Order bricks
Time (days) 1
2
3
4
5
6
7
8
9
10 11 12 13 14 15 16 17 18 19 20 21 22 23
Critical path analysis
New Wall No Activity 1 Excavate the trench 2 Pour the foundation 3 Raise the brickwork 4 Place the coping 5 Complete 6 Design 7 Order concrete 8 Order bricks
Time (days) 1
2
3
4
5
6
7
8
9
10 11 12 13 14 15 16 17 18 19 20 21 22 23
Critical path analysis
New Wall No Activity
Time (days) 1
2
3
4
5
6
1 Excavate the trench 2 Pour the foundation 3 Raise the brickwork 4 Place the coping 5 Complete 6 Design 7 Order concrete 8 Order bricks
Total Float
7
8
9
10 11 12 13 14 15 16 17 18 19 20 21 22 23
Clause 4.21 – progress reports
Clause 8.1 – notice of Commencement Date
To be submitted monthly until completion of all work
Comprehensive - shall include: a) Charts & descriptions of progress for each stage b) Photographs c) Manufacture report d) Contractor’s personnel & equipment e) QA documents, test results etc f)
Notices of claims
g) Safety statistics h) Comparisons planned versus actual progress, risks and mitigation measures 106
Clause 8.6 – rate of progress “If, at any time: a) Actual progress is too slow to complete within the Time for Completion, and / or b) Progress has fallen (or will fall) behind the current programme under Sub-Clause 8.3…
other than as a result of a cause listed in Sub-Clause 8.4 [Extension of Time]…
107
Clause 8.6 – rate of progress continued
…then the Engineer may instruct the Contractor to submit…a revised programme…
Unless the Engineer notifies otherwise, the Contractor shall adopt these revised methods, which may require increases in the working hours and / or in the numbers of Contractor’s Personnel or Goods, at the risk and cost of the Contractor…
108
Clause 8.6 – rate of progress continued
…If these revised methods cause the Employer to incur additional costs, the Contractor shall subject to Sub-Clause 2.5 [Employer’s Claims] pay these costs to the Employer, in addition to delay damages (if any) under Sub-Clause 8.7 below.”
London Array project has amended provisions Clause 8.6 in entitled expediting but covers similar matters AND Employer instructed acceleration
109
Exercise – Yellow Book The Contractor falls behind programme with certain non-critical activities. The Engineer instructs the Contractor to revise his methods of working to recover the delays and both the Employer and Contractor incur additional costs as a result.
Who pays?
110
Valuation & Payments
Valuation 1999 editions
Payment on a re-measurable basis (but option for lump sum)
Payment on a lump sum basis (but option for remeasurable)
Payment on a lump sum basis
Yellow Book Contract Price and Payments
Clauses 14.1 and 14.2 refer
Contract Price is lump sum (option for remeasurement)
Any quantities are estimated but may not be measurable (see particular conditions)
Any advance payment is subject to a guarantee and is progressively reduced as works proceeds
First interim payment also subject to issue of Performance Security
113
Yellow Book Payment Procedure
Clause 14.3 Contractor submits Statement at end of stated period – 6 copies in approved form and including supporting details (including progress report)
Clause 14.4 - Schedule of payments may apply. Payments may be adjusted for actual progress.
Clause 14.5 - Payment for plant and materials may apply – certain conditions attached
Clause 14.6 – Engineer issues Interim Payment Certificate within 28 days of receipt of Statement
Certificate does not indicate acceptance or approval London Array project has amended provisions. Clause 14.3 is not used, 14.4 is. Clause 14.5 is also not used. Clause 14.7 states invoice to be issued and that Employer reviews.
114
Yellow Book Payment Procedure
Clause 14.7 – Employer pays within 56 days of receipt of Statement (different for advance payment)
Clause 14.8 - Contractor entitled to interest for late payments without giving notice
Clause 14.9 – half retention release at issue of Taking Over certificate and passing Tests on Completion (plus success in the Tests after Completion if appropriate)
Clause 14.9 – remainder of retention release at expiry of Defects Notification Period unless still works to be done
London Array project has amended provisions. Clause 14.7 states 45 days payment period after issue. Clause 14.9 is not used.
115
Yellow Book Payment Procedure
Clause 14.10 – Contractor issues Statement at Completion within 84 days of Taking Over certificate. Engineer certifies as Interim Payment Certificate
Clause 14.11 – Contractor submits draft final statement within 56 days of receipt of Performance Certificate (issued under Clause 11.9 and confirms Contractor has met all obligations and works accepted)
When agreed, Contractor issues Final Statement
London Array project has amended provisions Clause 14.10 revised and 14.11 is not used.
116
Yellow Book Payment Procedure
Clause 14.12 – At same time Contractor also issues discharge that amount is in full and final settlement
Clause 14.13 – Engineer issues Final Payment Certificate within 28 days of receipt of above
Clause 14.7 – Employer pays within further 56 days
London Array project has amended provisions. Clauses 14.12 & 14.13 are not used
117
Exercise – Yellow book The Contractor issues its fifth statement for interim payment in the required format. Progress is behind what is expected and there is disagreement to the value of some varied works. The Engineer enters into discussion with the Contractor to agree adjustments to the applied amount and agreement is finally reached some 4 weeks later. The Engineer duly certifies an amount to be paid, 34 days after the receipt of the statement. The Employer pays the Contractor 2 days later.
What should the Contractor do?
118
Variations
Variations Clause 13 1. Can no longer be instructed after issue of the Taking Over Certificate 2. New procedure whereby Contractor may be requested to indicate effect on programme and value of works of a proposed change 3. Contractor has limited rights to object to a variation, but can be over ruled 4. Timely notice to claim additional payment is condition precedent to payment
120
Variations
Clause 13.1 does not set out the types of changes that can be made i.e. authority for variations
A variation is defined (Clause 1) as “a change to the Employer’s Requirements”
121
Procedure
Clause 3.3 states that the Contractor must comply with all instructions from the Engineer
Clause 13.1 says Contractor shall execute and be bound by Variation unless certain specific situations exist. If so, Contractor to give ‘prompt’ notice.
Clause 13.3 also provides for a Contractor’s proposal to be requested prior to an variation being instructed
122
Contractor’s proposal covers a. The extent of the work (including design) to be performed and the timetable for completion.
Consider:
A comprehensive description
Direct effect on other parts of the works (time and cost)
Effect on ability to achieve Time for Completion
123
Contractor’s proposal covers b. Proposed modifications to programme and Time for Completion
Consider:
Requirements of Clause 8.3 to notify possible delays to the execution of the works i.e. delay Take Over by the Employer
Can only be shown using CPA (critical path analysis)
Prolongation costs
124
Contractor’s proposal covers c. Proposed adjustment to Contract Price
Consider:
Shall include reasonable profit
125
Valuation of variations
Adjustments to the Contract Price are to be agreed or determined by the Engineer
Reasonable profit is to be included
126
Exercise – Yellow book The Engineer requests a proposal under 13.1 prior to instructing a Variation. The Contractor responds claiming that the Variation will require the mobilisation of additional equipment in order to complete within the existing Contract time schedule, but alternatively, could be undertaken using the existing equipment but with the varied work being completed after the Contract completion date. Prices for both options were provided.
The Engineer instructs the Contractor to undertake the work.
What should the Contractor do?
127
Claims
Clause 2.5 – Employer’s claims
Employer or Engineer to give notice and particulars to the Contractor To be given as soon as possible after being aware of the event or circumstance that gives rise to claim Engineer to agree / fairly determine (clause 3.5) Can deduct monies due
129
Employer’s claims
Clause 2.5 provides for and sets out procedure
Claims include: Electricity, water & gas consumption – clause 4.19 Equipment & free issue materials – clause 4.20 Rejection / retesting – clause 7.5 Failure to do remedial work – clause 7.6 Revised methods cause additional costs – clause 8.6 Delay damages – clause 8.7 Failure to pass tests on completion – clause 9.4 Extension to Defects Notification Period – clause 11.3 Failure to insure – clauses 18.1 / 18.2 130
Clause 20.1 – Contractor’s claims
Notice is mandatory and to be submitted within 28 days of any event or circumstance that gives rise to entitlement
Notice is condition precedent to additional payment / extension of time
131
Clause 20.1 – Contractor’s claims
Records shall be kept, Engineer permitted to view
Fully detailed claim to be submitted within 42 days of any event or circumstance that gives rise to entitlement including full supporting particulars
Further claims to be submitted on a monthly basis if on-going
Final submission within 28 days of end of effects
London Array project has amended provisions. Clause 20.1 says fully detailed claim to be submitted within 30 days 132
Clause 20.1 – Contractor’s claims
Engineer to respond with 42 days of submission
May request further particulars but must respond on principles of claim
Interim payments allowed for amounts substantiated
Engineer to agree / fairly determine (clause 3.5)
London Array project has amended provisions. Clause 20.1 says Engineer to respond within 30 days
133
Contractor’s claims
Clause 20.1 provides for and sets out procedure
Claims include: Delayed drawings or instruction – clause 1.9 Late access or possession – clause 2.1 Setting out reference point errors – clause 4.7 Adverse unforeseeable conditions – clause 4.12 Extension of Time – clause 8.4 Interference with tests – clause 10.3 Variations – clause 13.3 Change in law – clause 13.7 Force Majeure – clause 19.4 134
Ground condition claims
135
Yellow Book
Clause 4.10 – Employer to make available all relevant site data.
Clause 4.10 – Contractor responsible for interpretation.
Clause 4.10 – Contractor deemed “to the extent that it was possible” to have identified all risks etc.
Clause 4.11 – sufficiency of tender
London Array project has amended provisions. Clause 4.10 says Contractor accepts responsibility for information provided by the Employer 136
Yellow Book
Clause 4.12 – Unforeseeable (refer clause 1.1.6.8) physical conditions and obstructions.
Notice to be given if adverse conditions met that are considered to be Unforeseeable
Continue with Works and comply with instructions
Submit claim in accordance with clause 20.1
Engineer to agree / fairly determine (clause 3.5)
Money adjustment is Cost and Engineer to take account of more favourable conditions elsewhere
London Array project has amended provisions. Physical conditions are defined within clause 4.12. Revision to 4.10 taken account of.
137
Exercise – Yellow Book On 1st June, the Contractor discovers what it considers to be an unforeseen physical obstruction when it is laying a submarine cable. The Contractor’s site manager sends an email to his counterpart giving notice. On 1st July, the Contractor submits an Application for Interim Payment and includes within it an amount of €200,000 and description of the additional works it has undertaken as a result. On 4th July, the Contractor submits its Progress Report for the preceding month and includes within the list of notices submitted, a reference to the unforeseen physical obstruction and the aforementioned email.
Is the Contractor entitled to be paid anything in the next Interim Payment?
138
Extension of Time claims
Extension of Time
An Extension of Time does not mean an entitlement to additional money
An Extension of Time relieves Contractor liability to pay delay damages
An Extension of Time establishes a new completion date
An Extension of Time allows the Employer to impose delay damages after the new completion date
140
Extensions of Time - considerations
Contract provisions define the basis of entitlement
Delay to be on the critical path
‘Ownership’ of Float
Effect of Concurrency
141
Clause 8.4 – Extension of Time
Clause 8.4 - Lists grounds for entitlement
Yellow Book (a) to (e) Clause 8.4 - Refers to clause 20.1 i.e. notice, submissions of details Clause 8.4 – entitlement if completion for Taking Over is delayed No provision for Engineer to unilaterally award Extension of Time
142
Delay analysis techniques
Time extensions after completion of project (retrospective): Collapsed As-built As-planned –v- As-built (plus Windows Analysis)
Retrospective or Actual Based Analysis
Activity
1
2
3
4
5
6
7
8
9
10 11
ACTIVITY A ACTIVITY B
Original Completion
ACTIVITY C
Why Delay?
144
Delay analysis techniques
Time extensions after completion of project (retrospective): Collapsed As-built As-planned –v- As-built (plus Windows Analysis) Time extensions during currency of project (prospective) Impacted As-Planned Time Impact Analysis
Prospective or Model Based Analysis
Activity
ACTIVITY A ACTIVITY B
1
2
3
4
5
6
7
8
9
10 11
Event Original Completion
ACTIVITY C Estimate of Delay
146
Suspension
147
Suspension Clause 8.8
Engineer may instruct at any time
Contractor to protect, store, secure the work
If cause of suspension the responsibility of Contractor, no entitlement to time and / or money
148
Suspension Clause 8.9
Provides entitlement for Contractor to claim additional time and / or money
Notice must be given
Failure to protect, store or secure means no entitlement to time and / or money
149
Suspension Clause 8.10
Payment for Plant and Materials delivered to site
If:
Suspension > 28 days
And;
Plant and Materials marked as Employers property
150
Suspension Clause 8.11 If suspension > 84 days, Contractor may request Engineer permission to proceed.
If no response within 28 days: i.
Treat as an omission (cl. 13) if part of work, or
ii. Give notice of termination (cl. 16.2) if whole of work
151
Suspension Clause 8.12
Joint examination before work restarts
Contractor to make good any deterioration, defects or losses
152
Force Majeure
153
Force Majeure Clause 19
Clause 19.1 – definition
Clause 19.2 – notice to be given by either party within 14 days of event
Clause 19.2 – shall not apply to making payments
Clause 19.3 – reasonable endeavours to minimise resulting delay
Clause 19.4 – entitlement for Contractor to claim time and / or money
Clause 19.5 – treatment when differing terms in sub-contracts
154
Force Majeure Clause 19 Clause 19.6 – if period > 84 days for substantially all works, OR multiple periods > 140 days Either party can give notice of termination. Then proceed in accordance with cl. 16.3 Payment provisions described
Clause 19.7 – release from performance under Law
155
Completion & Handover
156
Typical Sequence of Events
Taking over Certificate
Commencement Date
Contractor Delay
Time for Completion
Completion
Clause 8.1 – Notice of Commencement Date
Clause 8.2 – Time for Completion
Clause 9.1 – Contractor’s Obligations for Tests on Completion including provision of As builts and O & M manuals
Clause 10.1 - Taking Over Certificate for the Works and Sections
Clause 10.2 - Taking Over Certificate for Parts of the Works
Clause 12.1 – Contractor’s Obligations for Tests After Completion
158
Exercise
What does the issue of the Taking Over certificate signify?
What are the consequences of the issue of the Taking Over Certificate?
159
Clause 8.7 – delay damages
Amount as agreed between the parties
Not subject to reduction for partial completion
Whether Employer has suffered damage is not relevant
Refers to sub-clause 2.5 (procedure)
Comprises Contractor’s entire liability for delay
160
Exercise
The Contractor gives the Engineer 14 days notice for issue of a Taking Over Certificate, undertaking to complete subsequently certain minor Works. The Engineer responds 21 days later by requiring that certain minor outstanding works (which effects maintenance of the Plant) be complete first. The Contractor claims EOT and costs.
161
Defects Notification Period
162
Defects Liability
Clause 11.1 – Completion of outstanding work and remedying defects
Period stated in Appendix
Clause 11.9 – Performance Certificate
163
Exercise – Yellow Book
What does the issue of the Performance certificate signify?
What are the consequences of the issue of the Performance Certificate?
164
Dispute resolution
Resolution of Disputes under Yellow Book If not agreed, Engineer to fairly determination (cl. 3.5). Any dispute can be referred to the procedure in cl. 20:
Adjudication by a Dispute Adjudication Board (DAB) in accordance with the rules in the standard form
If any Party dissatisfied or decision not made when it should, Notice of Dissatisfaction issued within 28 days
Arbitration in accordance with the Rules of Arbitration of the International Chamber of Commerce (ICC)
166
Yellow Book typical sequence of dispute events envisaged in clause 20
Parties present submissions to DAB